Tag Archives | New Homes

New Home In Nephi Utah

New Home In Nephi Utah

New Home In Nephi UtahBuild a new home in Nephi Utah for a fraction of the cost that we once built them for.  A brand new 1400 sq ft home can be purchased for under $180,000.00.  Our home are built with quality and care.  We have several to look at if you desire to see what type of home we build.

Check out one of our latest Windsor homes, located at 184 East 1450 North, located in Hunters Home subdivision.

You may also visit our inclusions part of the site to see what comes in each of our homes.

New Home In Nephi Utah

Call today for more information at (435) 623-2382.

New Home In Nephi Utah Related articles

 

At Priority Homes – We let You Choose

Utah Homebuilders

Image by SLV Native via Flickr

At Priority Homes – We let You Choose

Here is the color lost we use when we prepare your home.  We let you choose some the most basic items for your home.  We help guide you along and provide samples to ensure your home is just the way you want it.  Another reason to choose Priority Homes.

Call Today at (435) 623-2382 to learn more about our home choices in Santaquin and other Utah locations.  For your choice of Utah Homebuilders, choose Priority Homes.

 

Color Options:

 

Exterior:

Brick  / Rock Color – ___________________________________________

Stucco Color – ________________________________________________

Soffett and Fascia – _____________________________________________

Shingles – _____________________________________________________

 

 Interior :

Windows: _____________________________________________________

(White, Tan, Brown)

Paint (Main) ___________________________________________________

Paint (Base and Trim) ____________________________________________

Door Hardware _________________________________________________

(Brass, Nickel, Antique Nickel)

Carpet _________________________________________________________

Tile ____________________________________________________________

Cabinets ________________________________________________________

Counter tops _____________________________________________________

Utah Homebuilders

 

Enhanced by Zemanta

New Homes in Nephi – Near Red Cliff Elementary

New Homes in Nephi

Image via Wikipedia

New Homes in Nephi

Live Only 30 Minutes From Provo – Homes …

1411 S 200 E
Nephi, UT 84648

$170,00000
Property Details:
Sq. Feet: 1400 ft.
Acres: 0.27
Year Built: 2011
Bedrooms: 3
Bathrooms: 2
Cooling: Central Air
Heating: Forced Air
Garage: 2 Car
Description:
Priority Homes, Also known as Priority Land LLC, has been in the building business for over 10 years. We specialize in residential and commercial projects. Priority Homes is known for quality housing at a competitive price. Located in Nephi, Utah – Centrally located in the State of Utah, we are able to travel to all areas within the State of Utah. 

Currently, we are building homes in Nephi beginning at 170k. These homes are located in the Nephi in several locations throughout the city.

Contact us at 1-435-623-2382 for further questions or details.

http://www.priorityland.net

 

 

 

 

 

Enhanced by Zemanta

Affordable New Homes In Nephi

New Homes In Nephi

New Homes In Nephi

Buy a new 1200 sq ft home in Nephi for under 160k.  All of our homes feature 3 bedrooms and 2 baths and are located in beautiful Nephi.  Nephi is located just 30 minutes from Provo along Interstate 15.  Priority Homes offers new homes in Nephi for a great affordable price.  See the inclusions below.

Why Buy New Homes In Nephi, See Our Inclusions below.

Priority Homes Inclusions and Standard Practices

 Exterior Veneer

  • Front Elevation (Brick/Stone and Stucco)
  • Sides and Rear – Stucco
  • Full House Brick Upgrade – Price depending Upon size of home

 Floor Furnishings

  • $23.00 Mid-grade carpet with 5/8” pad (Client may pick out color)
  • Kitchen – Tile – $3.00 per Tile Budget
  • Bathrooms – Lin. Finishing
  • Entry Way – Tile – $3.00 per Tile Budget
  • Upgrades – Tile Choice and  or Tile throughout home

Shingle Details

  • 30 Year Shingle – Architectural Shingle

 Insulation

  • Exterior Walls insulated with – R-13
  • Roof Insulation – R-38
  • Basement Insulation – draped onto the walls just below frost line (R-19)
  • Upgrades – Interior Walls around Bathrooms (Change Order will be required and price determined at said time.)  Extra – $300.00

Appliances – $1800.00 budget – Black or White in Color  / Upgrades (Stainless Steel)

  • Refrigerator
  • Stove
  • Microwave
  • Dish Washer

Finish Work

  • All Paint grade material
  • All Shelving – Paint grade material (Particle Board)
  • Master Closet – Standard Closet organizer.  Bunk of shelves in the center

Cabinets and Countertops

  • Laminate Countertops throughout the home
  • Cabinets Knotty Alder  (Cabinets can be upgraded to 2 different colors to the Knotty Alder Cabinet
  • Upgrades countertops to Solid surface – (Change Order will be required and price determined at said time.)  Extra – $1500.00
  • Client may choose colors

Back Patio

  • 10′ x 12 Concrete Patio

Finish Hardware

  • All hardware on doors, such as: handles, hinges are antique nickel or equiv.

Doors

  • Front Door depending upon design will be metal or fiberglass.  Sidelights may be part of the home design if room allows.
  • All side and garage entry doors are Metal, painted to color of metal trim or black
  • Inside doors are 4 or 2 panel doors; hollow doors.

Bathroom Details 

  • Master Bath
    • White Porcelain sink with chrome fixtures
    • Tub / Shower – Porcelain with Cultured Marble surround.
    • Cabinets  – Knotty Alder (Natural Color)
    • Countertops – Laminate
    • Floors – Lin. Or equiv.
  • Main Bath
    • Tub / Shower  – Vinyl Insert
    • Chrome Fixtures
    • Cabinets – Knotty Alder (Natural Color)
    • Countertops – Laminate
    • Floors – Lin. Or equiv.

  Kitchen Details 

  • Knotty Alder Cabinets (Natural Color)
  • Countertops – Laminate
  • Appliances – See Budget Black or white Appliances
  • Floors – Tile (See Tile information.)
  • Sinks – Stainless Steel with Chrome Fixtures
    • All sinks have sprayer included

  Electrical Fixtures

  • All Fixtures are Antique Nickel or equiv.
  • Outlet Plugs – Place per code every 10 feet

Outside Concrete

  • Driveway included as per city code and garage width
  • Sidewalks
    • Sidewalk from Driveway to front door included
    • All exterior doors that are designed will have a concrete entry way ( 2 ft x 2 ft) before entering the home

Grading

  • All grading will be completed as per code.  Code states all grading is a negative grade from the home on a 2% slope.
  • Does not include top soil finish
  • Does not include Landscaping components, e.g. Sprinklers, top soil, sod, etc.

For more information about new homes in Nephi call Travis today at 435-623-2382.

Call Now For New Homes In Nephi – at 435.623.2382 for More Information.  

New Homes In Nephi Related articles

Enhanced by Zemanta

Buy New Homes In Santaquin, Utah

Buy New Homes In Santaquin, Utah

Buy New Homes In Santaquin, Utah

We are now offering great affordable homes for sale in the Santaquin Utah area.  We have over 30 lots to choose from and over 10 house plans to view.  Call Travis today at (435) 623-2382.   Below we have included a sample contract which is a standard REPC located on the State’s website.

Contractor Agreement

ARTICLES OF AGREEMENT

Made the _3rd______________day of _May___2011_

THE PARTIES TO THIS CONTRACTOR AGREEMENT ARE:

 


Physical Address:



Telephone Number:


(hereinafter referred to as “the Owner”)

AND

LRI Construction


Physical Address:


License Number:

Utah License 5832172-5501


(435) 623-0897


Telephone Number:

LRI Contruction


(hereinafter referred to as “the Contractor”)

The parties choose the above stated addresses as their physical addresses for purposes of delivery of any notice, payment of any amount and at which legal proceedings may be instituted. Each of the parties will be entitled at any time by way of written notice to the other to change the information regarding their physical addresses.

Whereas the Owner is desirous of constructing a

New Home built on new purchased parcel


New Home consists of 1407 sq ft with 2 Car Garage


(hereinafter referred to as “the Works”)

 

at the following address

 


(hereinafter referred to as “the Property”)

in accordance with the drawings and specifications annexed hereto, and signed by the parties:

and whereas the Contractor has agreed to execute the said Works on the Property in accordance with the drawings and specifications annexed to this Contractor Agreement and signed by the parties.

 

IT IS HEREBY AGREED AS FOLLOWS:

1.    For the consideration hereinafter mentioned, the Contractor will execute and complete the Works in accordance with the terms and conditions and drawings and / or the specifications annexed hereto.

1.1.    The Owner will pay the Contractor the sum of


(hereinafter referred to as the “Contract Sum”)

CONDITIONS:

2.    It is agreed that the drawings and specifications mentioned in this Contractor Agreement and annexed hereto are the final drawings and specifications of the Works and form an integral part of this Agreement. It is furthermore agreed that there shall be no additions or variations to the said drawings and / or specifications without the written consent of the other party first having been obtained.

2.1.    The Contractor undertakes to obtain the necessary approval from the local authority or other statutory body concerned for the Works as described herein. The Contractor shall hold the Owner harmless for any violations and shall accordingly indemnify the Owner.

2.2.    The Owner warrants that he is the registered owner of the Property. In the event of the property not being registered in the name of the Owner, then the Contractor shall be informed in writing by the Owner accordingly.

2.3.    In the event of the Local Authority, Mortgager or other statutory body or the Owner, at any time or for any reason whether before, during or after the construction of the Works, requiring any alteration, variation or amendment to the drawings and / or specifications involving the Contractor in additional expense, then the cost of complying with such alteration, variation or amendment shall be borne and paid for by the Owner.

PAYMENT:

3.    The Contractor shall be entitled to receive progress payments as the Works proceed in accordance with the provisions set out hereunder:

3.1.    The Contract Sum shall be paid in the following installments:

3.1.1.    Owner Shall Pay the Draw Sheets as given by the General Contractor.  Draw sheets will not exceed 5 occurances during the time of construction.  All final invoices will be paid on the last draw given to owners.

3.2.    Where the Contract Sum is to be paid on the Owner’s behalf by a finance company, Building Society, Bank or other institution, the Owner shall be responsible for signing all necessary documentation to enable the Contractor to receive payment as per the schedule as set out in 3.1.

COMMENCEMENT AND COMPLETION:

4.    Possession of the Property shall be given to the Contractor on ______February 1, 2011______ who shall complete the Works within _____12_____weeks, calculated from the date of possession. In the event of the holiday period of the Building Industry falling within the completion period, then the completion date shall be extended by ____5___ days.

4.1.    The Contractor may not commence the Works until –

4.1.1.    the necessary approval, consent or other authority required under any law (including any statute, ordinance, by-law and / or regulation) has been obtained by the Contractor and / or

4.1.2.    the mortgage bond where applicable has been registered and other forms of finance have been approved and / or

4.1.3.    required facilities such as electricity, water and toilet facilities are available on the Property, free of charge.

4.2.    For purposes of this Contractor Agreement, except where expressly stated otherwise, the date of completion shall be the date on which the Works is completed and when the Property has been cleared of all rubble and building debris as generated during construction.

4.3.    If completion of the Works is delayed as a result of major or unforeseen circumstances, including but not limited to any strike, lock out, shortages of materials, riot, political or civil disturbance, exceptionally inclement weather or any variation, act or omission on the part of the Owner or any other cause beyond the Contractor’s control, then:

4.3.1.    the Owner shall not for such reason have any claim against the Contractor whether for damages or otherwise;

4.3.2.    the Contractor shall be entitled to a fair and reasonable extension of time for the completion of the Works.

4.4.   Should the Contractor not be able to commence or proceed with the execution of the Works due to any act or omission on the part of the Owner then, in such event:

4.5.    If the Contractor fails to complete the Works within the period stipulated in the preceding sub-clause or any extended period authorized in writing by the Owner, then the Contractor shall pay the Owner as liquidated and ascertained damages, the penalty amount of $___100____ per day for the period during which the said Works shall so remain incomplete and the Owner may deduct such damages from any monies due to the Contractor.

DEFECTS LIABILITY:

5.    Subject to the provisions of the following paragraph, the Contractor undertakes that: any patent defect or other faults which may appear within 24 months of completion of the Works due to materials or workmanship not in accordance with this Contract, shall within a reasonable time after receipt of the Owner’s written instruction be made good by the Contractor and unless otherwise mutually agreed upon, at his own cost; provided that the Contractor shall not be required to make good at his own cost any damage after completion, unless it is agreed that such damage is due to injury which took place before completion.

5.1.    The Contractor shall only be responsible in terms of the preceding paragraph for damages sustained by the Owner under conditions of normal use and service and shall under no circumstances be responsible for damage or loss caused by wear and tear, misuse, neglect, negligence, abuse or accident or in respect of or arising from any risk insured against in terms of home owner’s insurance policies normally issued by a reputable insurance company in respect of residential properties and the Contractor shall under no circumstances be liable for any consequential loss or damage.

5.2.    The Contractor shall, however, not be liable under any circumstances whatever for any faults or defects caused by sub-surface water, settlement occurring in the ground below, normal shrinking or geological disturbances.

OWNERSHIP OF MATERIALS:

6.    Any unfixed materials required for the Works and delivered to the Property under this Contractor Agreement shall remain the property of the Contractor until they have been paid for by the Owner in terms of clause 3 and any unfixed surplus materials remain the property of the Contractor.

INSURANCE:

7.    The Contractor shall insure against Public Liability on or about the Works from the date of commencement mentioned in Clause 4 until the Works have been completed. The Contractor expressly guarantees that Workman’s Compensation is paid up and complied with. The Contractor shall insure against all risks to 100% of the insurable value of the Works.

INTERFERENCE:

8.    The Owner shall not have the right, either personally or through his agent, to issue instructions to, or interfere, hinder or obstruct any of the Contractor’s workmen, any sub-contractors employed on the Works or other persons employed by or acting on behalf of the Contractor.

8.1.    Should the Contractor incur any expense or loss beyond that provided for in, or reasonably contemplated by this Contractor Agreement due to the actions on the part of the Owner as described in Clause 4.4 or Clause 8, then the value of such expense or loss shall be assessed between the Owner and the Contractor and such agreed value shall be paid to the Contractor on completion of the Works.

OWNER’S DEFAULT:

9.    If the Owner does not pay the Contractor as provided for in Clause 3 or is in default in any other manner, the Contractor shall be entitled to forthwith cease work under this agreement until the Owner has made payment or until such default has been rectified.

9.1.    The time during which such Works shall cease shall operate as an extension of the time for completion of the Works.

9.2.    Should the default referred to in Clause 9 continue for a period exceeding 14 days, the Contractor shall be entitled to give the Owner 7 days written notice, by registered mail, of his intentions to terminate the Contractor Agreement.

9.3.    In addition to suspending work in terms of this Clause, the Contractor may, after giving 7 days written notice, determine the Agreement, if the Owner’s estate’s provisionally sequestrated or provisionally wound up as insolvent, or should the Owner commit a breach of any of the terms of this Contractor Agreement, all of which terms shall be material, without prejudice to any other rights which the Contractor may have in terms of this Agreement or in law.

9.4.    Should this Contractor Agreement be determined by the default of the Owner, then the Contractor shall be paid liquidated and ascertained pre-estimate of damages in the sum of 20% of the Contract Sum provided that the above provisions shall in no way preclude any other right or remedy that the Contractor may have in law.

9.5.    A Certificate signed by the Contractor’s Auditor specifying the amount due by the Owner to the Contractor shall be sufficient proof of any amount due to the Contractor in terms of this Agreement and may be used by the Contractor for the purposes of obtaining judgment whether by default or otherwise, summary judgment or provisional sentence against the Owner in any Court of Law having jurisdiction in respect thereof.

CONTRACTOR’S DEFAULT:

10.    If the Contractor shall make default in any of the following respects

10.1.    without reasonable cause wholly suspend the Works before completion, or

10.2.    refuses to proceed with the Works with reasonable diligence, or

10.3.    refuses after notice in writing from the Owner, to remove defective work or improper materials, then, if such default shall continue for 14 days after a registered letter from the Owner specifying the same, the Owner may, without prejudice to any other rights he may have in terms of this Contractor Agreement or in law, by registered post, determine the employment of the Contractor under this Agreement, provided no dispute has been declared in terms of Clause 14. In such event the Contractor shall be liable for all damages incurred by the Owner by reason of such default.

10.4.    If the Contractor’s estate is sequestrated as insolvent or if, being a company, it is placed under voluntary or compulsory liquidation, the Owner may, without prejudice to any other rights contained herein, by written and registered notice determine the employment of the Contractor under this Agreement.

MATERIALS IN SHORT SUPPLY:

11.    In the event of any of the materials set out in the Specification hereto being in short supply or unavailable for an unreasonable amount of time, then the Owner shall select substitute material of a similar quality from amongst like material readily procurable by the Contractor. Any difference in price shall be for the account of the Owner.

VARIATIONS:

12.    All variations, authorized or required by the Owner, shall be carried out and the Contract Sum adjusted, the valuation being assessed on the basis of the valuation of similar work included in this Contractor Agreement. Any variation to the Contracted Sum must be in writing and signed by both parties.

JURISDICTION:

13.    The parties hereby expressly consent to the jurisdiction of the Local Court even though such claim may otherwise exceed that Court’s jurisdiction to adjudicate on any dispute arising out of this Contractor Agreement which is not otherwise subject to arbitration in terms hereof. This is subject to the provision that if a party elects to institute action in a higher Court, he / she shall be entitled to do so.

ARBITRATION:

14.    Any dispute or difference between the Contractor and the Owner arising out of and during the currency of the Agreement or upon termination or cancellation thereof, shall be referred to arbitration. The arbitrator shall be appointed at the request of either party by the relevant Association having jurisdiction in the area.

PARTY STATUS:

15.    The Contractor is not an employee of the Owner but is working in his/her capacity as an independent contractor. The Contractor shall hold Owner harmless and thereby indemnify Owner for any claims including but not limited to liability insurance, worker’s compensation and withholding of tax for Contractor’s employees.

LIEN RELEASE:

16.     The Contractor will provide receipt of payments, lien releases and final lien releases from all subcontractors and suppliers immediately when they become due.

RIGHT TO CANCEL:

17.    Either party shall have the right to cancel this Contractor Agreement within 3 (three) days of signing it without incurring any penalties whatsoever. Cancellation must be in writing and delivered to the stated address of the other party.

ENTIRE AGREEMENT:

18.1.    This agreement and any exhibit attached constitute the sole and entire contractor agreement between the parties with regard to the subject matter hereof and the parties waive the right to rely on any alleged express provision not contained herein.

18.2.    No agreement varying, adding to, deleting from or canceling this agreement and no waiver of any right under this agreement shall be effective unless it is:

18.2.1.    In writing;

18.2.2.    Agreed to by both parties;

18.2.3.    Signed by both parties.

18.3.    No relaxation by a party of any of its rights in terms of this agreement at any time shall prejudice or be a waiver of its rights (unless it is a written waiver) and it shall be entitled to exercise its rights hereafter as if such relaxation had not taken place.

18.4.    No party may cede any of its rights or delegate or assign any of its obligations in terms of this contractor agreement without the prior written consent of the other parties.

 

 

 

 

Signed at ______________________on this ______day of _________________20____

 

SIGNATURE _____________________________(Owner)

Owner’s Full Names:

Michael and Ella Dunn


 

WITNESS 1:    _____________________________

SIGNATURE  ________________________________(Contractor)

Contractor’s Legal Name:

LRI INC.


 

WITNESS 1:    _____________________________

 

 

Detail of Extras

 

 

Enhanced by Zemanta

Perfect Weather for A New Home In Santaquin

Perfect Weather for A New Home In SantaquinThe weather this fall has been beautiful.  Because of the nice weather, it has allowed us to continue to build and provide beautiful homes for our clients.  Click here to hear from some of our clients.

Here at priority Homes we are dedicated in providing the very best home for the best price available.  We are building homes in Santaquin in the lower 170’s.  Click on our lot choice and see what lots we have available in Santaquin today.

To contact us for more information, simply call us at (435) 623-2382.

 

 

Enhanced by Zemanta

Stone Hollow Subdivision in Santaquin – Learn more

Learn more about the Stone Hollow Subdivision in Summit Ridge, Santaquin – Utah.  There are lots availalbe right now to build on and to start today.  Review the attached map of Stone Hollow below:

Stone Hollow Subdivision in Santaquin

Enhanced by Zemanta

Utah Home Builders In Utah County

Utah Home Builders In Utah County

Image via Wikipedia

Utah Home Builders In Utah County

If you are looking for a Utah home builder, you have come to the right place.  We specialize in taking care of you and your family.  Yes, it is true…. we are not the largest home building company in Utah, but we are the most customer oriented home builder in Utah.   Contact us today at (435) 623-2382 to learn more about what homes we offer and where we can build a new home for you.

Syracuse has various national and local home builders. You can search online for sale of new homes and new homing communities in Syracuse. Below you will find information about home builders and their homing communities in Syracuse.

Richmond American Homes – Richmond American is a national new home builder which has built units for 150,000 families across US. Richmond American Homes has two housing communities in Syracuse, Utah. Learn more about each Richmond American Homes community and their by visiting them online.

Ivory Homes – Ivory is a local city home builder catering to the demands of people of Syracuse, Utah. It has been building homes for forty years now. Ivory homes have three subdivisions in Syracuse which are named Fairmont estates, San Melia and Siena Vilaas. These houses range from $230,000 – $300,000. Learn more about the pricing, status, and location by visiting them online.

Benchmark Homes – Benchmark is another local home builder in Syracuse. They are known for their innovative designing at affordable prices. In Syracuse, Benchmark homes have over three communities with pricing starting from $230,000. They also provide “ready to move-in spec homes” at affordable prices. To get an insight into these new home communities visit them online.

KB Homes – KB is a national home builder building homes across US for the past fifty years. They are known for their dedicated designing. In Syracuse, KB homes have three new home communities. The pricing of this community start from $250,000. Visit KB homes online for more information about their floor plans, home pricing, new designs and subdivisions in Syracuse.

FieldStone Homes – FieldStone is a national home builder building homes across US for the last twenty years. In Syracuse, FieldStone homes “has ready to move-in” houses and three new homing communities. The pricing of homing communities lies in the range of $200-$350K. To know Location, features, and floor plans of these communities visit FieldStone online.

Silverstone Homes – Silverstone is a local home builder building communities in north Utah. Silverstone has a new community named, Wasatch Villas. The pricing of this community starts from $250,000. To know about upcoming communities and their locations and pricing by visiting Silverstone online.

Paul is a principal of NewHomesSection. Search Salt Lake home builders and new homes Salt Lake today!

Article Source: http://EzineArticles.com/?expert=Paul_Escobedo

Article Source: http://EzineArticles.com/1351637

 

 

Enhanced by Zemanta

 

 

 

Find A New Home In Santaquin that’s Affordable

Find A New Home In Santaquin that’s Affordable

We are building new homes in Santaquin beginning in the 170’s.  We have lots in Summit Ridge, which is the new community on the Southwest side of Santaquin.

Find A New Home In Santaquin that's Affordable

Our new homes in this area are appraising for more than $210,000.00.  Walk into instant equity as you purchase a new home from Priority Homes LLC.

Call today at (435) 623-2382 for more information.

 

Find A New Home In Santaquin that’s Affordable

Enhanced by Zemanta

Utah Houseplans

Utah Houseplans

Utah Houseplans Related articles

Utah Houseplans

Enhanced by Zemanta